Terms of Service.

These Terms of Service govern your use of the VidurNexus Technologies website and any services we provide. By engaging with us, you agree to these terms.

1. Services

VidurNexus Technologies provides custom software engineering services including, but not limited to: web and mobile application development, AI system design, cloud infrastructure, and deep technology research and development.

The specific scope, timeline, and deliverables for each engagement are defined in a separate project agreement or statement of work signed by both parties.

2. Enquiries & Project Agreements

Submitting a contact form on our website does not constitute a contract or commitment by either party. An engagement begins only upon execution of a formal written agreement, which outlines scope, timeline, payment terms, and deliverables.

3. Payment Terms

Payment terms are defined in each project agreement. Unless otherwise agreed:

• A deposit (typically 30–50% of project value) is required before work commences
• Milestone payments are due upon completion of each defined milestone
• Final payment is due prior to delivery of final files or deployment to production

Late payments may result in suspension of work. We reserve the right to charge interest on overdue amounts at 2% per month.

4. Intellectual Property

Upon receipt of full payment, the client owns all custom code, designs, and deliverables produced specifically for their project ("Work Product"). VidurNexus retains ownership of any pre-existing tools, frameworks, libraries, or proprietary methodologies used in delivery.

VidurNexus reserves the right to display completed work in its portfolio, case studies, and marketing materials unless the client explicitly requests confidentiality in writing.

5. Confidentiality

Both parties agree to keep confidential any proprietary information, trade secrets, or sensitive business data shared during the engagement. This obligation survives termination of the project agreement.

6. Warranties & Limitation of Liability

We warrant that our work will be performed with reasonable care and skill. We do not warrant that software will be entirely free of bugs or that it will meet requirements beyond those specified in the project agreement.

To the maximum extent permitted by applicable law, VidurNexus's total liability for any claim arising from our services shall not exceed the total amount paid by the client for the specific project giving rise to the claim.

We are not liable for indirect, incidental, consequential, or punitive damages.

7. Termination

Either party may terminate a project agreement with 14 days' written notice. In the event of termination, the client is liable for payment for all work completed up to the termination date. Deposit amounts are non-refundable unless VidurNexus is in material breach of the agreement.

8. Governing Law

These terms and any project agreements are governed by the laws of India. Any disputes shall be subject to the exclusive jurisdiction of the courts of India.

9. Changes to These Terms

We may update these Terms of Service from time to time. Updated terms will be posted on this page with a revised date. Continued use of our website after changes constitutes acceptance of the new terms.

10. Contact

If you have questions about these terms, please contact us:

VidurNexus Technologies
India
vidurnexus@gmail.com